Tag: time impact analysis

Apr 24

Delay Analysis Techniques: Selecting the Right Methodology | E-Basel

By Basel Al Najjar in Construction Claims
April 24, 2026

Claims · Methodology Delay Analysis Techniques: Selecting and Applying the Right Methodology How to choose between CPM, APAB, TIA, and Windows Analysis. Strengths, limitations, and best practice application in FIDIC arbitration. 7 min read · Updated 24/04/2026 By Basel Al Najjar Civil Engineering Consultant, DIAC Arbitrator, Tribunal Chairman and Accredited Expert Witness. Over two decades …

acceleration impact analysis construction, as-planned as-built analysis, baseline vs as-built programme analysis, concurrent delay identification techniques, construction arbitration delay analysis, contract programme compliance analysis, CPM scheduling delay analysis, critical path method delay, critical path validation techniques, delay allocation methodologies, delay analysis best practices construction, delay analysis techniques construction, delay causation analysis construction, delay claim substantiation techniques, delay damages assessment techniques, delay event identification methods, delay expert report methodology, delay methodology selection, delay mitigation evaluation techniques, delay modelling software Primavera P6, delay quantification methods construction, dynamic vs static delay analysis, earned value delay indicators, FIDIC delay analysis approaches, float analysis construction delay, forensic delay analysis construction, fragnet analysis construction delays, impacted as-planned method, Monte Carlo simulation schedule delays, near-critical path delay analysis, productivity loss vs delay analysis, programme disruption analysis methods, prolongation cost analysis methods, retrospective vs prospective delay analysis, schedule impact modelling construction, schedule risk analysis delay, schedule update analysis delay, SCL delay analysis protocol, time impact analysis, windows analysis delay

Permanent link to this article: https://www.e-basel.com/construction-claims/delay-analysis-techniques-selecting/

May 28

Thematic Analysis of Concurrent Delays in Transportation Infrastructure Projects

By Basel Al Najjar in Construction Claims
May 28, 2023

Thematic Analysis of Concurrent Delays in Transportation Infrastructure Projects Thematic Analysis of Concurrent Delays Concurrent delays refer to situations where multiple events or factors contribute to a delay in the completion of a construction project. These delays can occur simultaneously and impact the overall timeline of the project. In the context of infrastructure projects related …

acceleration techniques, causes, Change orders, Concurrent delays, Construction claims, construction delays, construction projects, contractual disputes, CPM, critical path analysis, delay analysis, Dispute resolution, disruption events, impacts, mitigation strategies, PERT, Project Management, Project Scheduling, Resource Allocation, Risk Management, schedule delays, stakeholder coordination, time extensions, time impact analysis, transportation infrastructure

Permanent link to this article: https://www.e-basel.com/construction-claims/thematic-analysis-of-concurrent-delays-in-transportation/

About the Expert

Basel Al Najjar

Civil Engineering Consultant · Accredited Expert Witness
Arbitrator · Senior Project Manager

Specialising in construction claims, FIDIC contracts, and dispute resolution across the UAE. Acting as Arbitrator, Tribunal Chairman, and Independent Expert in high-value, multi-party disputes.

Instruct e-Basel →

Core Services Quick-Links

⚖️
Construction Claims Consultant
›

📋
FIDIC Expert Witness
›

📊
Delay Analysis Expert
›

🏛️
Construction Arbitrator
›

⏱ FIDIC Notice Deadline Calculator

Select your contract edition and book, choose the relevant clause, then enter the date you became aware of the triggering event. All applicable notice deadlines will be calculated instantly.

FIDIC Edition

Contract Type

Trigger Event / Clause

Date of Awareness / Event Occurrence

The date you became aware, or should have become aware, of the event giving rise to the claim or notice obligation.

Key Notice Periods at a Glance

1999 editions — Cl. 20.1 Notice: 28 days · Detailed Claim: 42 days
2017 editions — Cl. 20.2 Notice: 28 days · Detailed Claim: 84 days
Unforeseeable Conditions (Cl. 4.12): Notice as soon as practicable
Defects Notification Period: 365 days from Taking-Over Certificate

Deadline Summary

Discuss Your Claim with an Expert →

Made with by Graphene Themes.

Tag: time impact analysis

Delay Analysis Techniques: Selecting the Right Methodology | E-Basel

Thematic Analysis of Concurrent Delays in Transportation Infrastructure Projects

Authority Bio

Core Services Quick-Links

Categories

About

Connect

Legal