Tag: impacted as-planned analysis

Apr 24

Time-Related Claims: EOT, Delay Analysis and Damages | E-Basel

By Basel Al Najjar in Construction Claims
April 24, 2026

Claims · Delay Analysis Time-Related Claims: Extension of Time, Delay Analysis and Damages How to assess delay events, quantify critical path impact, and calculate prolongation costs under FIDIC and UAE law. 8 min read · Updated 24/04/2026 By Basel Al Najjar Civil Engineering Consultant, DIAC Arbitrator, Tribunal Chairman and Accredited Expert Witness. Over two decades …

acceleration vs delay claims, as-built vs as-planned delay analysis, baseline vs updated programme delay, compensable delay claims, concurrent delay, concurrent delay analysis methods, constructive acceleration construction, critical path delay, critical path method CPM delay, delay analysis methods construction, delay analysis techniques, delay claim substantiation, delay damages calculation, delay event identification, delay expert analysis construction, delay mitigation strategies, delay notices requirements FIDIC, delay risk allocation construction, disruption vs delay claims, Eichleay formula overhead, Emden formula overhead, engineer determination EOT, EOT application procedure, EOT claims construction, excusable vs non-excusable delay, extension of time entitlement, extension of time EOT, float ownership construction, forensic delay analysis, head office overhead claims, Hudson formula overhead, impacted as-planned analysis, liquidated damages delay, liquidated damages vs actual damages, loss of productivity claims, non-compensable delay construction, project delay documentation, prolongation cost calculation, prolongation costs, schedule impact assessment, site overhead prolongation, time impact analysis TIA, windows analysis delay

Permanent link to this article: https://www.e-basel.com/construction-claims/time-related-claims-eot-delay-analys/

About the Expert

Basel Al Najjar

Civil Engineering Consultant · Accredited Expert Witness
Arbitrator · Senior Project Manager

Specialising in construction claims, FIDIC contracts, and dispute resolution across the UAE. Acting as Arbitrator, Tribunal Chairman, and Independent Expert in high-value, multi-party disputes.

Instruct e-Basel →

Core Services Quick-Links

⚖️
Construction Claims Consultant
›

📋
FIDIC Expert Witness
›

📊
Delay Analysis Expert
›

🏛️
Construction Arbitrator
›

⏱ FIDIC Notice Deadline Calculator

Select your contract edition and book, choose the relevant clause, then enter the date you became aware of the triggering event. All applicable notice deadlines will be calculated instantly.

FIDIC Edition

Contract Type

Trigger Event / Clause

Date of Awareness / Event Occurrence

The date you became aware, or should have become aware, of the event giving rise to the claim or notice obligation.

Key Notice Periods at a Glance

1999 editions — Cl. 20.1 Notice: 28 days · Detailed Claim: 42 days
2017 editions — Cl. 20.2 Notice: 28 days · Detailed Claim: 84 days
Unforeseeable Conditions (Cl. 4.12): Notice as soon as practicable
Defects Notification Period: 365 days from Taking-Over Certificate

Deadline Summary

Discuss Your Claim with an Expert →

Made with by Graphene Themes.

Tag: impacted as-planned analysis

Time-Related Claims: EOT, Delay Analysis and Damages | E-Basel

Authority Bio

Core Services Quick-Links

Categories

About

Connect

Legal